What does Disruption mean? Disruption describes reduced productivity on a construction project where work is impeded, re‑sequenced or performed inefficiently, so the contractor must deploy extra labour, plant or supervision, or work longer, to meet the programme—even if the completion date does not move. It is distinct from delay: delay concerns time overrun; disruption concerns loss of productivity and increased cost. In UK and Irish construction law, “disruption” is a descriptive term rather than a statutory definition. It is recognised in case law and managed under standard forms (for example JCT, NEC and RIAI) through change/compensation mechanisms or as damages for breach. Typical causes include...
Read More
A construction Contract will usually set out the date by which the works must be finished (the 'Completion date'). However, over the life of a construction project, events commonly arise that delay or disrupt progress, and may therefore hinder the contractor’s ability to achieve Completion by the completion date. Delay and disruption are among the most frequent drivers of claims and disputes on construction projects.
It is important to distinguish delay from disruption—in programme terms, this difference marks the line between critical and non-critical delay. Disruption is often, and wrongly, treated as the same as delay, and they are routinely discussed together (as 'delay and disruption') as though they were identical with identical consequences. Delay and disruption are, nonetheless, distinct concepts. Their implications are not the same. How either is addressed will depend on the particular cause in each instance and on their effect on the contractor’s ability to complete the works in accordance with the contractual programme and to meet the completion date. Definitions of these concepts follow below...
When evaluating a general damages claim, the practitioner ought initially to refer to the Judicial College Guidelines (JCG)...
This Practice Note This Practice Note reviews mechanisms used in settling litigation. A Tomlin order consists of a consent order paired with a schedule. It operates to stay proceedings on terms that have been agreed. The provisions contained in the schedule may remain confidential. This Practice Note describes the scope of confidentiality attaching to the schedule and sets out how it differs from a standard consent order. Sample wording for a Tomlin order is included, alongside links to precedents, as well as guidance on court approval. It also addresses varying, setting aside and enforcing a Tomlin order, including the considerations the court will take into account when handling applications for each. Further guidance is provided on interpreting and applying the relevant provisions of the CPR; however, some courts and divisions impose very specific requirements for both drafting and approval, and for approaching the schedule and confidentiality issues. Accordingly, you must consider the particular rules and court guide provisions in the forum where your claim is proceeding when drawing up the Tomlin order...
Date [ date ] Parties [ name of Landlord ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Landlord) [ name of Tenant ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Tenant) [ [ name of Guarantor ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Guarantor) ] [ [ name of Mortgagee ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Mortgagee) ] Definitions Within this Deed, the terms below shall be interpreted as follows: [ Annual Rent • the annual sum reserved under the Lease; ] [ Insurance Rent • the Tenant’s share of the Landlord’s costs of insuring the Property (as set out in the Lease); ] Lease • the lease of the Property dated [ date ], entered into between (1) [ the Landlord OR [ name ...
I, [ name ], of [ address ], solemnly and sincerely state that: [ Matters to be verified, set out in numbered paragraphs ] I make this solemn statement in good conscience, believing it to be true, and pursuant to the provisions of the Statutory Declarations Act 1835. DECLARED at [ details ] this [ day ] day of [ month and year ] Before me ................................................................................ [ signature of the person before whom the declaration is made ] A [ commissioner for oaths OR [ solicitor OR [ insert other qualification ] ] authorised to administer oaths ]...