This Practice Note outlines the nature and purpose of the Information Release Schedule (IRS), how it operates within JCT contracts, and key practical points to bear in mind when deploying the IRS and embedding it in a JCT agreement.
Under JCT, the IRS—see, for instance, the fifth recital of the JCT Standard Building Contract Without Quantities—sets out which information the Architect or Contract Administrator will issue, together with the timing of that release. In effect, it functions as a programme governing the orderly flow and delivery of design information.
An IRS is required on a project where comprehensive design data is not available at the tender documentation stage, or will still be incomplete by the time the contract is executed. This arises most acutely on fast‑track schemes, where external drivers—typically determined by the project’s business case, for example a harvest deadline on a manufacturing scheme—fix the completion date, and design must proceed in tandem with early construction activities to achieve that date. Whilst commonplace on fast‑track work, the IRS is also encountered on many other projects...
When evaluating a general damages claim, the practitioner ought initially to refer to the Judicial College Guidelines (JCG)...
This Practice Note This Practice Note reviews mechanisms used in settling litigation. A Tomlin order consists of a consent order paired with a schedule. It operates to stay proceedings on terms that have been agreed. The provisions contained in the schedule may remain confidential. This Practice Note describes the scope of confidentiality attaching to the schedule and sets out how it differs from a standard consent order. Sample wording for a Tomlin order is included, alongside links to precedents, as well as guidance on court approval. It also addresses varying, setting aside and enforcing a Tomlin order, including the considerations the court will take into account when handling applications for each. Further guidance is provided on interpreting and applying the relevant provisions of the CPR; however, some courts and divisions impose very specific requirements for both drafting and approval, and for approaching the schedule and confidentiality issues. Accordingly, you must consider the particular rules and court guide provisions in the forum where your claim is proceeding when drawing up the Tomlin order...
Date [ date ] Parties [ name of Landlord ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Landlord) [ name of Tenant ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Tenant) [ [ name of Guarantor ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Guarantor) ] [ [ name of Mortgagee ] [ of OR incorporated in England and Wales (company registration number [ number ]) with its registered office at ] [ address ] (Mortgagee) ] Definitions Within this Deed, the terms below shall be interpreted as follows: [ Annual Rent • the annual sum reserved under the Lease; ] [ Insurance Rent • the Tenant’s share of the Landlord’s costs of insuring the Property (as set out in the Lease); ] Lease • the lease of the Property dated [ date ], entered into between (1) [ the Landlord OR [ name ...
I, [ name ], of [ address ], solemnly and sincerely state that: [ Matters to be verified, set out in numbered paragraphs ] I make this solemn statement in good conscience, believing it to be true, and pursuant to the provisions of the Statutory Declarations Act 1835. DECLARED at [ details ] this [ day ] day of [ month and year ] Before me ................................................................................ [ signature of the person before whom the declaration is made ] A [ commissioner for oaths OR [ solicitor OR [ insert other qualification ] ] authorised to administer oaths ]...